CITY OF WINDSOR GENERAL CONDITIONS

TABLE OF CONTENTS

• GC 1 INTERPRETATION 3
• GC 1.01 CAPTIONS 3
• GC 1.02 GENDER AND SINGULAR REFERENCES
• 3 GC 1.03 DEFINITIONS 3
• GC 2 CONTRACT DOCUMENTS 6
• GC 2.01 GENERAL 6
• GC 2.02 ACCURACY OF DRAWINGS AS TO LOCATIONS OF STRUCTURES AND UTILITIES 7
• GC 2.03 SOUNDINGS, BORINGS & INSPECTION OF SITE 7
• GC 2.04 DOCUMENTS MUTUALLY EXPLANATORY 8
• GC 2.05 CUSTODY OF DRAWINGS 8
• GC 2.06 ORDER OF PRECEDENCE 8
• GC 3 ADMINISTRATION OF CONTRACT 9
• GC 3.01 ENGINEERS AUTHORITY 9
• GC 3.02 DUTIES AND POWERS OF ENGINEER’S REPRESENTATIVES 11
• GC 3.03 WORKING DRAWINGS 12
• GC 3.04 RIGHT OF THE ENGINEER TO MODIFY METHODS AND EQUIPMENT 13
• GC 3.05 ASSIGNMENT AND SUB-LETTING 13
• GC 3.06 WORKING AREA 14
• GC 3.07 REMOVAL OF WORKERS 14
• GC 3.08 SERVICE OF NOTICE ON CONTRACTOR 15
• GC 3.09 LAYOUT 15 GC 3.10 ACCESS TO SITE 15
• GC 3.11 EXAMINATION OF WORK BEFORE COVERING UP 16
• GC 3.12 QUALITY OF MATERIALS, WORKMANSHIP AND TESTS 16
• GC 3.13 PAYMENT FOR TESTING 17
• GC 3.14 URGENT REPAIRS 17
• GC 3.15 SUSPENSION OF WORK 18
• GC 3.16 EXTENSION OF TIME FOR COMPLETION 18
• GC 3.17 DELAYS 18
• GC 3.18 VARIATIONS 19
• GC 3.19 EXTRA WORK 20
• GC 3.20 ADDITIONAL WORK 20
• GC 3.21 CLAIMS, NEGOTIATIONS, MEDIATION, ARBITRATION 20
• GC 3.22 NOTICES 24
• GC 3.23 NOTICE OF COMPLETION OF WORKS 25
• GC 3.24 END OF MAINTENANCE PERIOD 25
• GC 3.25 ASSUMPTION OF WORKS 26
• GC 3.26 SITE MEETINGS 26
• GC 3.27 DEFAULT BY CONTRACTOR 26
• GC 4 CONTRACTOR’S RESPONSIBILITIES AND CONTROL OF THE WORK 28
• GC 4.01 GENERAL 28
• GC 4.02 LAYOUT 31
• GC 4.03 TRAFFIC CONTROL REQUIREMENTS 32
• GC 4.04 MAINTAINING ROADWAYS AND DETOURS 33
• GC 4.05 ACCESS TO PROPERTIES ADJOINING THE WORK AND INTERRUPTION OF UTILITY SERVICES 33